By accessing lagercoder.site or engaging K.K. Lagercoder Pvt. Ltd. for app development services, you agree to be bound by these Terms of Service. If you do not agree, please do not use our website or services.
K.K. Lagercoder Pvt. Ltd. provides mobile and web application development services. The specific scope, timeline, deliverables, and payment terms for each project are agreed upon in a written Project Agreement before work commences.
All development projects are governed by a separate Project Agreement signed by both parties. The Project Agreement takes precedence over these general Terms of Service in the event of any conflict.
Payment is milestone-based as specified in the Project Agreement. An advance payment (typically 30–50% of the total project value) is required before development begins. Subsequent payments are tied to agreed milestones.
Upon receipt of full payment, all source code and deliverables developed specifically for your project are transferred to you. We retain the right to use general methodologies, frameworks, and tools developed independently of your project.
You are responsible for providing accurate project requirements, timely feedback, and any third-party credentials or assets required for the project. Delays caused by the client may affect the project timeline.
Our liability is limited to the amount paid by you for the specific project or service in question. We are not liable for indirect, incidental, or consequential damages.
These Terms are governed by the laws of India. Any disputes shall be subject to the exclusive jurisdiction of the courts in Bengaluru, Karnataka.
For queries regarding these Terms, contact us at: lagercoder.site | +91 78457 84500.